Allen Ballew & Associates

Share

Tyrone, GA 30290

Company Info

  • Est. 1983
  • Size 1-4 Employees
  • Annual Vol Undisclosed

Featured Project Return to Projects List

Taxiway Extension - MCAS

Project Information

Project Location:
Beaufort, SC
Approx Contract:
$250,000
Status:
Completed
Structure Type:
Sewage / Water Treatment Plant

Scope Of Work

Our  Navy contract was delayed as a result of a defective design that required a redesign in order to comply with environmental requirements as set forth by South Carolina DHEC. The redesign effort came in iterations of responses to sixty (60) RFI and twenty (20) contract modifications.  Our  believed that they were entitled to remuneration for delay and estimated the amount at approximately $ 250,000. AB Consulting prepared a REA after reviewing all the documentation. The REA included CPM scheduling proofs, CPM frag-nets,  analysis, man-hour curves, delay narrative. AB Consulting participated in direct settlement negotiations with the Contracting Officer. We recovered $ 600,000 for our .

Project Images

#
#
Share URL copied!
https://www.thebluebook.com/iProView/357800/allen-ballew-associates/general-contractors/
Facebook
X
LinkedIn
Request Brochure

We will send a link to your email address that will download our FREE PDF brochure.